LW INFRASTRUCTURE PTE LTD v LIM CHIN SAN CONTRACTORS PTE LTD
[2012] BLR 1
HIGH COURT OF SINGAPORE
Judith Prakash J
Time at large — Liquidated damages — Delay to progress — No delay to completion caused by employer’s breaches — Termination of sub-contractor’s employment — Accrued rights to liquidated damages at termination — Whether liquidated or common law damages recoverable for period after termination — Contractual notice for liquidated damages.